France-Besançon: Construction work

Get tender notifications and more sign up now and never miss an opportunity again. Already a member? log in to your account.

Title	France-Besançon: Construction work
OJEU (High Value)	252850-2020
Type	Invitation to tender
Date Published	2020-06-02
Deadline	2020-07-10 12:00:00
Nature Of Contract	Public works contract
Awarding Authority
Procedure	Open procedure

Description :
CONTRACT NOTICE Section I: Contracting authority I.1) Name and addresses: Official name: Sedia mandataire CRBFC National registration number: National registration number: 77566535900102 Postal address: 6 rue Louis Garnier — BP 1513 Town: Besançon Cedex Postal code: 25008 Country: FR Telephone: +33 381412567 E-mail: D.fretard@sedia-bfc.fr NUTS code: FRC21 Main address: http://www.bourgognefranchecomte.fr Address of the buyer profile (URL): https://www.ternum-bfc.fr Communication I.3) Procurement documents (URL):http://www.ternum-bfc.fr Additional Information I.3.4) Additional information can be obtained from: I.3.6)Tenders or requests to participate must be submitted electronically via: https://marches.ternum-bfc.fr/?page=entreprise.EntrepriseAdvancedSearch&AllCons&refConsultation=63580&orgAcronyme=n5m I.4) Type of the contracting authority: REGIONAL AUTHORITY Main Activity I.5.1) Main Activity: GENERAL PUBLIC SERVICES Section II: Object of Contract Title: Lycée Pergaud — 25000 Besançon — restructuration de l'internat F Reference number: PERGAUDINTERNATF II.1.4) Short description ) — remplacement de la couverture tuiles — reprise des façades. Chantier de restructuration intérieure en quatre phases successives. 2 2 Information about lots II.1.6) This contract is divided into lots: yes II.1.6.7) The contracting authority reserves the right to award concessions combining the following lots or groups of lots - Néant. Description: Item/Lot 1 Title: Désamiantage — curage — déconstruction II.2.1) Lot No: 1 NUTS code: FRC21 II.1.4) Short description Désamiantage et déplombage selon diagnostics avant travaux — dépose des revêtements — déconstruction des chapes, du cloisonnement, plafonds, portes. II.2.5) Award criteria: II.02.07) Duration in months 47 II.2.7.5) This contract is subject to renewal: no II.2.10) Variants will be accepted: no The procurement is related to a project and/or programme financed by European Union funds): no Description: Item/Lot 2 Title: Terrassements — VRD — aménagements extérieurs II.2.1) Lot No: 2 NUTS code: FRC21 II.1.4) Short description Reprise des réseaux en pied de bâtiment — dispositif d'infiltration — aménagement de voirie — espaces verts et plantations. II.2.5) Award criteria: II.02.07) Duration in months 47 II.2.7.5) This contract is subject to renewal: no II.2.10) Variants will be accepted: no The procurement is related to a project and/or programme financed by European Union funds): no Description: Item/Lot 3 Title: Gros-œuvre II.2.1) Lot No: 3 NUTS code: FRC21 II.1.4) Short description Dallage reprise en sous-œuvre réservations — trémies consolidations créations et bouchements d'ouverture Installations de chantier — escaliers provisoires métalliques extérieurs. II.2.5) Award criteria: II.02.07) Duration in months 47 II.2.7.5) This contract is subject to renewal: no II.2.10) Variants will be accepted: no The procurement is related to a project and/or programme financed by European Union funds): no Description: Item/Lot 4 Title: Charpente bois — couverture tuile — zinguerie — étanchéité II.2.1) Lot No: 4 NUTS code: FRC21 II.1.4) Short description Reprise chevronnage et lattage — trémies dans charpente — remplacement couverture tuile — étanchéité sur galerie extérieures existantes. II.2.5) Award criteria: II.02.07) Duration in months 47 II.2.7.5) This contract is subject to renewal: no II.2.10) Variants will be accepted: no The procurement is related to a project and/or programme financed by European Union funds): no Description: Item/Lot 5 Title: Ossature bois — bardage bois — menuiseries extérieures bois-aluminium II.2.1) Lot No: 5 NUTS code: FRC21 II.1.4) Short description Mur à ossature bois en façades — menuiseries extérieures bois-aluminium — bardage composite. II.2.5) Award criteria: II.02.07) Duration in months 47 II.2.7.5) This contract is subject to renewal: no II.2.10) Variants will be accepted: no II.2.11) Options II.2.11.2) Description of options Remplacement isolant laine de roche par isolant laine de bois dans les murs à ossatures bois. The procurement is related to a project and/or programme financed by European Union funds): no Description: Item/Lot 6 Title: Traitement des façades — ITE II.2.1) Lot No: 6 NUTS code: FRC21 II.1.4) Short description Isolation thermique et enduit minéral — ravalement de façades. II.2.5) Award criteria: II.02.07) Duration in months 47 II.2.7.5) This contract is subject to renewal: no II.2.10) Variants will be accepted: no The procurement is related to a project and/or programme financed by European Union funds): no Description: Item/Lot 7 Title: Serrurerie — métallerie II.2.1) Lot No: 7 NUTS code: FRC21 II.1.4) Short description Blocs portes — grilles — garde-corps. II.2.5) Award criteria: II.02.07) Duration in months 47 II.2.7.5) This contract is subject to renewal: no II.2.10) Variants will be accepted: no The procurement is related to a project and/or programme financed by European Union funds): no Description: Item/Lot 8 Title: Menuiseries intérieures bois — signalétique II.2.1) Lot No: 8 NUTS code: FRC21 II.1.4) Short description Blocs portes — châssis vitrés — agencement — signalétique. II.2.5) Award criteria: II.02.07) Duration in months 47 II.2.7.5) This contract is subject to renewal: no II.2.10) Variants will be accepted: no The procurement is related to a project and/or programme financed by European Union funds): no Description: Item/Lot 9 Title: Plâtrerie — cloisons — doublages — projection feu — peinture — revêtements muraux — nettoyage II.2.1) Lot No: 9 NUTS code: FRC21 II.1.4) Short description Doublages et cloisonnements — flocage protection feu — peintures — nettoyage. II.2.5) Award criteria: II.02.07) Duration in months 47 II.2.7.5) This contract is subject to renewal: no II.2.10) Variants will be accepted: no The procurement is related to a project and/or programme financed by European Union funds): no Description: Item/Lot 10 Title: Plafonds suspendus II.2.1) Lot No: 10 NUTS code: FRC21 II.1.4) Short description Faux-plafonds laine de roche — faux-plafonds fibres de bois. II.2.5) Award criteria: II.02.07) Duration in months 47 II.2.7.5) This contract is subject to renewal: no II.2.10) Variants will be accepted: no The procurement is related to a project and/or programme financed by European Union funds): no Description: Item/Lot 11 Title: Revêtements de sols souples II.2.1) Lot No: 11 NUTS code: FRC21 II.1.4) Short description Ragréages — sols linoléum. II.2.5) Award criteria: II.02.07) Duration in months 47 II.2.7.5) This contract is subject to renewal: no II.2.10) Variants will be accepted: no The procurement is related to a project and/or programme financed by European Union funds): no Description: Item/Lot 12 Title: Revêtements de sols durs — faïences II.2.1) Lot No: 12 NUTS code: FRC21 II.1.4) Short description Étanchéité liquide sous carrelage de sol — système de protection à l'eau sous carrelage mural — carrelage de sols — faïence — chapes. II.2.5) Award criteria: II.02.07) Duration in months 47 II.2.7.5) This contract is subject to renewal: no II.2.10) Variants will be accepted: no The procurement is related to a project and/or programme financed by European Union funds): no Description: Item/Lot 13 Title: Appareil élévateur II.2.1) Lot No: 13 NUTS code: FRC21 II.1.4) Short description Ascenseur 630 kg. II.2.5) Award criteria: II.02.07) Duration in months 47 II.2.7.5) This contract is subject to renewal: no II.2.10) Variants will be accepted: no II.2.11) Options II.2.11.2) Description of options Contrat d'entretien réglementaire de l'ascenseur et contrat d'entretien étendu de l'ascenseur. The procurement is related to a project and/or programme financed by European Union funds): no Description: Item/Lot 14 Title: Plomberie — sanitaire II.2.1) Lot No: 14 NUTS code: FRC21 II.1.4) Short description Équipements locaux sanitaires — récupération eaux de pluie — réseaux de distribution et d'évacuation. II.2.5) Award criteria: II.02.07) Duration in months 47 II.2.7.5) This contract is subject to renewal: no II.2.10) Variants will be accepted: no The procurement is related to a project and/or programme financed by European Union funds): no Description: Item/Lot 15 Title: Chauffage — VMC — désenfumage II.2.1) Lot No: 15 NUTS code: FRC21 II.1.4) Short description Sous-station — distribution — radiateurs — ventilation — désenfumage mécanique. II.2.5) Award criteria: II.02.07) Duration in months 47 II.2.7.5) This contract is subject to renewal: no II.2.10) Variants will be accepted: no II.2.11) Options II.2.11.2) Description of options Remplacement des panneaux radiants en plafond des salles du rez-de-chaussée par radiateurs muraux. The procurement is related to a project and/or programme financed by European Union funds): no Description: Item/Lot 16 Title: Électricité — courants forts — courants faibles II.2.1) Lot No: 16 NUTS code: FRC21 II.1.4) Short description Distribution et équipements — éclairage — installation informatique — alarmes — système de sécurité incendie. II.2.5) Award criteria: II.02.07) Duration in months 47 II.2.7.5) This contract is subject to renewal: no II.2.10) Variants will be accepted: no The procurement is related to a project and/or programme financed by European Union funds): no Description: Item/Lot 17 Title: Installation photovoltaïque II.2.1) Lot No: 17 NUTS code: FRC21 II.1.4) Short description Installation de panneaux photovoltaïque sur couverture tuile. II.2.5) Award criteria: II.02.07) Duration in months 47 II.2.7.5) This contract is subject to renewal: no II.2.10) Variants will be accepted: no II.2.11) Options II.2.11.2) Description of options Contrat d'entretien étendu de l'installation photovoltaïque. The procurement is related to a project and/or programme financed by European Union funds): no Section III: Legal, economic, financial and technical information III.1.2) Economic and financial standing III.1.2.2) Selection criteria as stated in the procurement documents III.1.3) Technical and professional ability III.1.3.1.2) Selection criteria as stated in the procurement documents Section IV: Procedure IV.1.1) Type of procedure: Open IV.2.1) Time limit for receipt of tenders or requests to participate IV.2.2) Date 2020-07-10 IV.2.2) Local time 12:00 IV.2.6) Duration in months (from the date stated for receipt of tender): 6 IV.2.7) Conditions for opening of tenders IV.2.7) Date 2020-07-10 IV.2.7) Local time 14:00 Section V: Complementary information Additional Information: L'opération prévoit une clause obligatoire d'insertion par l'activité économique au titre de l'exécution des marchés des lots nº 1 à 17, sauf lots nº 13 et 16. Visite des lieux: visite obligatoire: une visite commune obligatoire et accompagnée est organisée pour les lots suivants: — lot 01 — désamiantage — curage — déconstruction, — lot 03 — gros-œuvre — installations de chantier, — lot 04 — charpente bois — couverture tuiles — étanchéité, — lot 05 — ossature bois — bardage bois — menuiseries extérieures bois-aluminium, — lot 14 — plomberie — sanitaire, — lot 15 — chauffage — VMC — désenfumage, — lot 16 — électricité — courants forts — courants faibles. 6 visites sont programmées et réservées pour ces lots: — mercredi 10.6.2020 (8h30), — mercredi 10.6.2020 (10h30), — mercredi 17.6.2020 (8h30), — mercredi 17.6.2020 (10h30), — mercredi 24.6.2020 (8h30), — mercredi 24.6.2020 (10h30). Ces visites communes à l'ensemble des six lots, seront dirigées par le maître d'œuvre et le mandataire du maître d'ouvrage les conditions impératives d'inscription et de participation aux visites sont spécifiées dans le règlement de consultation. Il ne sera pas possible de visiter les lieux à d'autres dates visite facultative: il n'est pas prévu de visite facultative pour les autres lots. Review body: Official name: Tribunal administratif de Besançon Postal address: 30 rue Charles Nodier Town: Besançon Postal code: 25000 Country: FR Telephone: +33 381826000 E-mail: Greffe.ta-besancon@juradm.fr Fax: +33 381826001 VI.04.04) Service from which information about the review Official name: Greffe du tribunal administratif de Besançon Postal address: 30 rue Charles Nodier Town: Besançon Postal code: 25000 Country: FR Telephone: +33 381826000 E-mail: Greffe.ta-besancon@juradm.fr Fax: +33 381826001 Section VI Date of dispatch of this notice : 2020-05-28

Description :

CONTRACT NOTICE

Section I: Contracting authority

I.1) Name and addresses:
Official name: Sedia mandataire CRBFC

National registration number:

National registration number: 77566535900102
Postal address: 6 rue Louis Garnier — BP 1513
Town: Besançon Cedex
Postal code: 25008
Country: FR
Telephone: +33 381412567

E-mail:

D.fretard@sedia-bfc.fr
NUTS code: FRC21

Main address:

http://www.bourgognefranchecomte.fr

Address of the buyer profile (URL):

https://www.ternum-bfc.fr

Communication
I.3) Procurement documents
(URL):http://www.ternum-bfc.fr

Additional Information
I.3.4) Additional information can be obtained from:
I.3.6)Tenders or requests to participate must be submitted electronically via:
https://marches.ternum-bfc.fr/?page=entreprise.EntrepriseAdvancedSearch&AllCons&refConsultation=63580&orgAcronyme=n5m
I.4) Type of the contracting authority: REGIONAL AUTHORITY

Main Activity

I.5.1) Main Activity: GENERAL PUBLIC SERVICES

Section II: Object of Contract

Title:

Lycée Pergaud — 25000 Besançon — restructuration de l'internat F

Reference number: PERGAUDINTERNATF

II.1.4) Short description
) — remplacement de la couverture tuiles — reprise des façades. Chantier de restructuration intérieure en quatre phases successives.
2
2

Information about lots

II.1.6) This contract is divided into lots: yes

II.1.6.7) The contracting authority reserves the right to award concessions combining the following lots or groups of lots -
Néant.

Description: Item/Lot 1

Title:

Désamiantage — curage — déconstruction

II.2.1) Lot No: 1
NUTS code: FRC21
II.1.4) Short description
Désamiantage et déplombage selon diagnostics avant travaux — dépose des revêtements — déconstruction des chapes, du cloisonnement, plafonds, portes.

II.2.5) Award criteria:

II.02.07) Duration in months 47
II.2.7.5) This contract is subject to renewal: no
II.2.10) Variants will be accepted: no

The procurement is related to a project and/or programme financed by European Union funds): no

Description: Item/Lot 2

Title:

Terrassements — VRD — aménagements extérieurs

II.2.1) Lot No: 2
NUTS code: FRC21
II.1.4) Short description
Reprise des réseaux en pied de bâtiment — dispositif d'infiltration — aménagement de voirie — espaces verts et plantations.

Title:

Gros-œuvre

II.2.1) Lot No: 3
NUTS code: FRC21
II.1.4) Short description
Dallage reprise en sous-œuvre réservations — trémies consolidations créations et bouchements d'ouverture Installations de chantier — escaliers provisoires métalliques extérieurs.

Title:

Charpente bois — couverture tuile — zinguerie — étanchéité

II.2.1) Lot No: 4
NUTS code: FRC21
II.1.4) Short description
Reprise chevronnage et lattage — trémies dans charpente — remplacement couverture tuile — étanchéité sur galerie extérieures existantes.

Title:

Ossature bois — bardage bois — menuiseries extérieures bois-aluminium

II.2.1) Lot No: 5
NUTS code: FRC21
II.1.4) Short description
Mur à ossature bois en façades — menuiseries extérieures bois-aluminium — bardage composite.

II.2.5) Award criteria:

II.02.07) Duration in months 47
II.2.7.5) This contract is subject to renewal: no
II.2.10) Variants will be accepted: no
II.2.11) Options
II.2.11.2) Description of options
Remplacement isolant laine de roche par isolant laine de bois dans les murs à ossatures bois.

The procurement is related to a project and/or programme financed by European Union funds): no

Description: Item/Lot 6

Title:

Traitement des façades — ITE

II.2.1) Lot No: 6
NUTS code: FRC21
II.1.4) Short description
Isolation thermique et enduit minéral — ravalement de façades.

Title:

Serrurerie — métallerie

II.2.1) Lot No: 7
NUTS code: FRC21
II.1.4) Short description
Blocs portes — grilles — garde-corps.

Title:

Menuiseries intérieures bois — signalétique

II.2.1) Lot No: 8
NUTS code: FRC21
II.1.4) Short description
Blocs portes — châssis vitrés — agencement — signalétique.

Title:

Plâtrerie — cloisons — doublages — projection feu — peinture — revêtements muraux — nettoyage

II.2.1) Lot No: 9
NUTS code: FRC21
II.1.4) Short description
Doublages et cloisonnements — flocage protection feu — peintures — nettoyage.

Title:

Plafonds suspendus

II.2.1) Lot No: 10
NUTS code: FRC21
II.1.4) Short description
Faux-plafonds laine de roche — faux-plafonds fibres de bois.

Title:

Revêtements de sols souples

II.2.1) Lot No: 11
NUTS code: FRC21
II.1.4) Short description
Ragréages — sols linoléum.

Title:

Revêtements de sols durs — faïences

II.2.1) Lot No: 12
NUTS code: FRC21
II.1.4) Short description
Étanchéité liquide sous carrelage de sol — système de protection à l'eau sous carrelage mural — carrelage de sols — faïence — chapes.

Title:

Appareil élévateur

II.2.1) Lot No: 13
NUTS code: FRC21
II.1.4) Short description
Ascenseur 630 kg.

II.2.5) Award criteria:

II.02.07) Duration in months 47
II.2.7.5) This contract is subject to renewal: no
II.2.10) Variants will be accepted: no
II.2.11) Options
II.2.11.2) Description of options
Contrat d'entretien réglementaire de l'ascenseur et contrat d'entretien étendu de l'ascenseur.

The procurement is related to a project and/or programme financed by European Union funds): no

Description: Item/Lot 14

Title:

Plomberie — sanitaire

II.2.1) Lot No: 14
NUTS code: FRC21
II.1.4) Short description
Équipements locaux sanitaires — récupération eaux de pluie — réseaux de distribution et d'évacuation.

Title:

Chauffage — VMC — désenfumage

II.2.1) Lot No: 15
NUTS code: FRC21
II.1.4) Short description
Sous-station — distribution — radiateurs — ventilation — désenfumage mécanique.

II.2.5) Award criteria:

II.02.07) Duration in months 47
II.2.7.5) This contract is subject to renewal: no
II.2.10) Variants will be accepted: no
II.2.11) Options
II.2.11.2) Description of options
Remplacement des panneaux radiants en plafond des salles du rez-de-chaussée par radiateurs muraux.

The procurement is related to a project and/or programme financed by European Union funds): no

Description: Item/Lot 16

Title:

Électricité — courants forts — courants faibles

II.2.1) Lot No: 16
NUTS code: FRC21
II.1.4) Short description
Distribution et équipements — éclairage — installation informatique — alarmes — système de sécurité incendie.

Title:

Installation photovoltaïque

II.2.1) Lot No: 17
NUTS code: FRC21
II.1.4) Short description
Installation de panneaux photovoltaïque sur couverture tuile.

II.2.5) Award criteria:

II.02.07) Duration in months 47
II.2.7.5) This contract is subject to renewal: no
II.2.10) Variants will be accepted: no
II.2.11) Options
II.2.11.2) Description of options
Contrat d'entretien étendu de l'installation photovoltaïque.

The procurement is related to a project and/or programme financed by European Union funds): no

Section III: Legal, economic, financial and technical information

III.1.2) Economic and financial standing
III.1.2.2) Selection criteria as stated in the procurement documents
III.1.3) Technical and professional ability
III.1.3.1.2) Selection criteria as stated in the procurement documents

Section IV: Procedure

IV.1.1) Type of procedure: Open

IV.2.1) Time limit for receipt of tenders or requests to participate
IV.2.2) Date 2020-07-10
IV.2.2) Local time 12:00

IV.2.6) Duration in months (from the date stated for receipt of tender): 6
IV.2.7) Conditions for opening of tenders
IV.2.7) Date 2020-07-10
IV.2.7) Local time 14:00

Section V: Complementary information

Additional Information:

L'opération prévoit une clause obligatoire d'insertion par l'activité économique au titre de l'exécution des marchés des lots nº 1 à 17, sauf lots nº 13 et 16. Visite des lieux: visite obligatoire: une visite commune obligatoire et accompagnée est organisée pour les lots suivants:

— lot 01 — désamiantage — curage — déconstruction,

— lot 03 — gros-œuvre — installations de chantier,

— lot 04 — charpente bois — couverture tuiles — étanchéité,

— lot 05 — ossature bois — bardage bois — menuiseries extérieures bois-aluminium,

— lot 14 — plomberie — sanitaire,

— lot 15 — chauffage — VMC — désenfumage,

— lot 16 — électricité — courants forts — courants faibles.

6 visites sont programmées et réservées pour ces lots:

— mercredi 10.6.2020 (8h30),

— mercredi 10.6.2020 (10h30),

— mercredi 17.6.2020 (8h30),

— mercredi 17.6.2020 (10h30),

— mercredi 24.6.2020 (8h30),

— mercredi 24.6.2020 (10h30).

Ces visites communes à l'ensemble des six lots, seront dirigées par le maître d'œuvre et le mandataire du maître d'ouvrage les conditions impératives d'inscription et de participation aux visites sont spécifiées dans le règlement de consultation. Il ne sera pas possible de visiter les lieux à d'autres dates visite facultative: il n'est pas prévu de visite facultative pour les autres lots.

Review body:
Official name: Tribunal administratif de Besançon
Postal address: 30 rue Charles Nodier
Town: Besançon
Postal code: 25000
Country: FR
Telephone: +33 381826000

E-mail:

Greffe.ta-besancon@juradm.fr
Fax: +33 381826001

VI.04.04) Service from which information about the review
Official name: Greffe du tribunal administratif de Besançon
Postal address: 30 rue Charles Nodier
Town: Besançon
Postal code: 25000
Country: FR
Telephone: +33 381826000

E-mail:

Greffe.ta-besancon@juradm.fr
Fax: +33 381826001

Section VI

Date of dispatch of this notice : 2020-05-28

CPV Codes
45000000; 45111100; 45262660; 45112000; 45233140; 45232410; 45223220; 45261420; 45261000; 45421000; 45262650; 45443000; 44316500; 45421141; 45440000; 45343100; 45421146; 45432111; 45431000; 45313100; 45330000; 45331000; 45311200; 45310000; 45311000; 45312000; 09331200; Construction work; Demolition work; Asbestos-removal work; Excavating and earthmoving work; Roadworks; Sewerage work; Structural shell work; Waterproofing work; Erection and related works of roof frames and coverings; Joinery work; Cladding works; Facade work; Smiths' wares; Installation of partitioning; Painting and glazing work; Fireproofing work; Installation of suspended ceilings; Laying work of flexible floor coverings; Tiling work; Lift installation work; Plumbing and sanitary works; Heating, ventilation and air-conditioning installation work; Electrical fitting work; Electrical installation work; Electrical wiring and fitting work; Alarm system and antenna installation work; Solar photovoltaic modules;

CPV Codes

45000000; 45111100; 45262660; 45112000; 45233140; 45232410; 45223220; 45261420; 45261000; 45421000; 45262650; 45443000; 44316500; 45421141; 45440000; 45343100; 45421146; 45432111; 45431000; 45313100; 45330000; 45331000; 45311200; 45310000; 45311000; 45312000; 09331200; Construction work; Demolition work; Asbestos-removal work; Excavating and earthmoving work; Roadworks; Sewerage work; Structural shell work; Waterproofing work; Erection and related works of roof frames and coverings; Joinery work; Cladding works; Facade work; Smiths' wares; Installation of partitioning; Painting and glazing work; Fireproofing work; Installation of suspended ceilings; Laying work of flexible floor coverings; Tiling work; Lift installation work; Plumbing and sanitary works; Heating, ventilation and air-conditioning installation work; Electrical fitting work; Electrical installation work; Electrical wiring and fitting work; Alarm system and antenna installation work; Solar photovoltaic modules;

Sign-up now to receive weekly OJEU reports for the UK, your sector and/or elsewhere in the EU. We also report on the procurement of EC Institutions.

Start